Get A Demo
Get Access Now

Access Denied!!!

It appears that you are using a private browser which blocks some scripts necessary for this page to function properly. As a result, you may experience limited functionality or the page may not work at all.

To access this page, please consider using a different browser or switch to the standard version of Firefox.

Thank you for your understanding.

Florida (FL)

>

Port St Joe

>

32456

Access Full Project

Publicly Funded

Privately Funded

Bidding Soon

Documents Available

Addenda Available

Post-Bid

Post-Bid

Back to Results
Previous
Next

Saving Project...

Full details on over 250,000 Projects including 2000 updated daily available to subscribers

December 12, 2023

January 11, 2024

April 11, 2024

Multiple Locations

Paving, Site Work

No Information to Display

$773,482.00

Public - County

img_map_placeholder

Multiple Locations, Port St Joe, FL

31

7

6

2

Subscribe to View Full Documents

As of January 10, 2024 this project was awarded to Roberts & Roberts with the awarded amount of $7773,482.01 Construct an Asphalt Concrete pavement based on the type of work specified in the Contract and the Asphalt Work Categories as defined below. Meet the applicable requirements for plants, equipment, and construction requirements as defined below. Use an asphalt concrete mix that meets the requirements of this specification. The Gulf County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing This project includes approximately 0.59 miles of roadway resurfacing on Madison Street in Gulf County, FL. Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $1,699.00 per day. All bidders shall be FDOT Qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Construction, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant Mix-Bituminous Course and have an active sams.gov registration. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. All questions must be submitted to Clay Smallwood, P.E. at csmallwood@gulfcounty-fl.gov The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County.

6 Record(s)

Subscribe to Get All Contact Details

Trades

Division 00 - Lorem Ipsum

Division 00 - Lorem Ipsum

Lorem, Ipsum, Dolor, Sit amet
Subscribe to See All Trade Details

You’ve Reached the Free View Limit

Want to see more project and bidder data in your market? Check out our product options and see what works best for you and your business.

Come back in [[refresh_days]] to get [[project_count]] more free projects.

Related Projects