Reference Number 0000328089 In order to be an eligible bidder, interested parties must reach out to the city of Pleasanton and request to be added to the plan holder list. See Notice to Bidders for more information Job Pleasanton, California In general, this work will consist of removal and replacement of 8-inch, 10-inch, and 18-inch sewer mains; reconstruction of existing manhole inverts; construction of new manholes; removal or abandonment of existing sewer mains and manholes; installation of drop wyes; realignment of sewer lateral; reconnection of existing sewer laterals; traffic control; providing and implementing water pollution control measures; and restoration of roadway, hardscape, and landscape. The Engineer's cost estimate for the project is $750,000. Question Acceptance Deadline 08/30/2023 at 5:00 PM PT Questions are submitted online No -- Questions should be directed to the project engineer either in-person at 200 Old Bernal Avenue, Pleasanton, California, by mail at P.O. Box 520, Pleasanton, California 94566- 0802, by phone at (925) 931-5650, or by email at snguyen@cityofpleasantonca.gov. General Requirements - Certified Payroll - Contractors License Required - Insurance Required - Required Bonding Requirements - Bid Bond 10 % - Performance Bond 100 % - Maintenance Bond 10 % - Labor and Materials Bond 100 % Each Bid Proposal shall be accompanied by either cash, a cashier's check or a certified check, amounting to not less than ten percent of the bid, payable to the order of the City of Pleasanton or by a bond for that amount and payable in the form contained in this bid package. The successful Bidder will be required to furnish performance and payment bonds, each in an amount not less than one hundred percent (100%) of the contract price, and a maintenance bond not less than ten percent (10%) of the contract price. As provided in California Business & Professions Code Section 7028.15, the City has determined that at the time of bid, the Contractor shall possess a valid Class A General Engineering Contractor or C-34 Pipeline Contractor license. *The City reserves the right to reject any or all bids and to determine which bid is, in the City's judgment, the lowest responsive and responsible bid of a Bidder or group of Bidders. fully complete the project within sixty (60) working days after start of work. Bidder shall pay as liquidated damages in the sum of $2,000.00 per calendar day