This is for a Firm Fixed Price Contract. See Solicitation Section J for list of documents (Page 38). Construction Wage Determination - Cowlitz County - "General Decision Number: WA20220067 07/22/2022, Superseded General Decision Number: WA20210067 Site Visit: 08/15/2022, 10:00 PM (PDT). Please confirm if you plan to attend send email to cindy_salazar@fws.gov. Submit proposals to Cindy Salazar via email: cindy_salazar@fws.gov Any changes will be posted as an amendment. Response date: see block 13 Final date for Request for Information (RFI) by end of day on 08/22/2022. If any questions send your RFI via email to cindy_salazar@fws.gov Magnitude - Price Range: Between $1,000,000 and $5,000,000. Delivery: 10/31/2024 Delivery Location Code: 0008349202 FWS ABERNATHY FTC 1440 ABERNATHY CREEK ROAD LONGVIEW WA 98632-9764 US COMMENCEMENT, PROSECUTIONS, AND COMPLETION OF WORK (APR 1984) The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 760 days after issuance of the Notice to Proceed (NTP). The time stated for completion shall include final cleanup of the premises. Rehab Intake Structure Period of Performance: 09/01/2022 to 10/31/2024 LR1 Rehab Intake Structure The rehabilitation of the existing hatchery intake structure involves three (3) main components: The diversion, adult fish ladder and demo of the existing inclined screen structure. (a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government. (b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract. (c) A claim under this clause shall not be allowed-- (1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and (2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.